NOTICE OF REQUEST FOR STATEMENT OF QUALIFICATIONS CITY OF SANDPOINT- 2018 CIPP PROJECT Pursuant to IC 67-2805, "Procurement of Public Works Construction", City of Sandpoint (City), Idaho is requesting Statements of Qualifications (SOQ) from licensed public works contractors who are interested in bidding on the 2018 CIPP Project. The Project generally consists of cured-in-place pipe rehabilitation of approximately 5,000 to 6,000 linear feet of 8-inch to 10-inch sanitary sewers, including cleaning, CCTV inspection, cutting off protruding taps, reinstating laterals, and related items of work. Actual bid quantities may change pending the ongoing final design of the project. The opinion of estimated project cost is between $180,000 and $225,000. It is anticipated that the project will bid in March of 2018 with a contract duration of approximately forty (40) calendar days from the commencement of Contract Times, and must be Substantially Complete by August 31, 2018. Actual bid quantities and dates are subject to change. The City reserves the right to cancel or postpone bidding or award of a contract for the project. The Request for SOQ Information Packet contains the project description, SOQ Form and requirements, and evaluation criteria. Contractors must submit a response in the format outlined in the Request for Statement of Qualifications. Any response may be withdrawn prior to the scheduled time below for the opening of the responses or authorized postponement thereof. Copies of the Request for SOQ Information Packet may be obtained from: City of Sandpoint, Public Works Department, Attn: Darlene Edwards, Public Works Administrative Assistant, 1123 Lake Street, Sandpoint, ID 83864; Phone: (208) 263-3407; Email darlene@sandpointidaho.gov. The completed SOQ and required forms must be received by the City Clerk at the location listed below prior to 2:00 PM PST on March 16, 2018. Mark the envelope in which the response is enclosed with: City of Sandpoint, 2018 CIPP Project - Statement of Qualifications. Responses may be submitted to: City of Sandpoint, Attn: Maree Peck, City Clerk, 1123 Lake Street, Sandpoint, ID 83864. Alternatively, the SOQ may be submitted by e-mail by submitting to the City Clerk at: mpeck@ sandpointidaho.gov. It is the contractor's responsibility to confirm receipt. All responses must be signed and respondents must have a currently-valid Idaho Public Works Contractor license and Specialty Construction Category for the work under consideration. This Request for SOQ is not a solicitation to bid. The City does not intend to award a contract based on this solicitation or to otherwise pay for information solicited herein. Upon receipt of SOQs, the City will evaluate and determine which contractors are qualified to bid. If the City proceeds with bidding of the project, all respondents deemed qualified by the City will be invited to submit formal bids for the project as delineated in the Bidding Documents, which are currently under development. The City, in accordance with Title VI of the Civil Rights Act of 1964, 78 stat. 252, 42 U.S.C. 2000d to 2000d-4 and Title 49, Code of Federal Regulations, Department of Transportation, Subtitle A, Office of the Secretary Part 21, Nondiscrimination in Federally-assisted programs of the Department of Transportation issued pursuant to such Act, hereby notifies all bidders that it will affirmatively ensure that in any contract entered into pursuant to the advertisement, disadvantaged business enterprises as defined at 49 CFR Part 23 will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, national origin, or sex in consideration for an award. Any protest of determination of qualifications or bidding procedures will be handled in accordance with procedures delineated in IC 67-2805. Respondents will be responsible for all costs (including site visits, if any) incurred in preparing or responding to this Request for Qualifications. Maree Peck, City Clerk City of Sandpoint, Idaho SNP LEGAL 5219 MARCH 2, 9, 2018

SUMMONS FOR PUBLICATION Case No. CV42-18-0095 IN THE DISTRICT COURT OF THE FIFTH JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF TWIN FALLS ROBERT MEYERS and KATHI MEYERS, husband and wife, Plaintiffs, vs. JED PETTERSON; DEPARTMENT OF THE TREASURY acting through THE INTERNAL REVENUE SERVICE, Defendants. TO: JED PETTERSON: You have been sued by Robert Meyers and Kathi Meyers, husband and wife, the Plaintiffs, in the District Court in and for Twin Falls County, Idaho, Case No. CV42-18-0095. he nature of the claim against you is for monies due and owing and foreclosure. Any time after 21 days following the last publication of this summons, the court may enter a judgment against you without further notice, unless prior to that time you have filed a written response in the proper form, including the case number, and paid any required filing fee to the Twin Falls County District Court, Clerk of the Court, 425 Shoshone St. North, Twin Falls, Idaho 83301, (208) 736-4119, and served a copy of your response on the Plaintiffs' attorney, David A. Coleman, Coleman, Ritchie & Cluff, 156 2nd Ave. West, PO Box 525, Twin Falls, Idaho 83303-0525, (208)734-1224. A copy of the Summons and Complaint can be obtained by contacting either the Clerk of the Court or the attorney for the Plaintiffs. If you wish legal assistance, you should immediately retain an attorney to advise you in this matter. DATED: 2/9/18 CLERK OF THE DISTRICT COURT BY: /S/: Elisha Raney Deputy Clerk SNP LEGAL 5187 FEBRUARY 16, 23, MARCH 2, 9, 2018

SUMMONS CASE NO. CV 2017-01380 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF BONNER FELTEN INVESTMENTS, LLC, a Colorado limited liability company Plaintiffs, vs. SANDY WOLTERS, a single woman, and ANDREW D. MARTIN and STEPHANIE S. MARTIN, Trustees of the MARTIN FAMILY REVOCABLE TRUST, dated February 1, 2010; and any and all heirs, beneficiaries, successors, assigns or other persons claiming any right, title or interest in and to that real property described as follows: A portion of the real property located in Section 22, Township 57 North, Range 2 West, B.M., Bonner County, Idaho, described in that certain deed recorded with the Bonner County, Recorder on December 3, 1945, in Book 72 of Deeds, Page 249 as Instrument No. 18176, more particularly described as follows: The West Half (W1/2) of that real property lying between the sidelines of South Fourth Avenue in the City of Sandpoint, Idaho, from the south end of South Fourth Avenue, extending to the ordinary mean high water line of Lake Pend Oreille, as it existed as of the date of statehood and prior to construction of any dams regulating the elevation of Lake Pend Oreille, situated in the City of Sandpoint, Idaho, County of Bonner, State of Idaho. Defendants. NOTICE TO DEFENDANT: ANY AND ALL HEIRS, BENEFICIARIES, SUCCESSORS ASSIGNS OR OTHER PERSONS CLAIMING ANY RIGHT, TITLE OR INTEREST IN AND TO THE REAL PROPERTY INDICATED IN THE CAPTION YOU HAVE BEEN SUED BY THE ABOVE-NAMED PLAINTIFF. READ THE INFORMATION BELOW: You have been sued by FELTEN INVESTMENTS, LLC, a Colorado limited liability company, the Plaintiff, in the District Court in and for County, Idaho, Case No. CV- 2017-01380. The nature of the claim against you is an action for Quiet Title and Declaratory Relief. Any time after 20 days following the last publication of this summons, the court may enter a judgment against you without further notice, unless prior to that time you have filed a written response in the proper form, including the Case No., and paid any required filing fee to the Clerk of the Court at Bonner County District Court, 215 South First Avenue, Sandpoint, ID 83864, Phone 208-265-1432, and served a copy of your response on the Plaintiff's attorney at Featherston Law Firm, Chtd., 113 South Second Avenue, Sandpoint, Idaho, 83864, Phone: (208) 263-6866, Fax (208) 263-0400. A copy of the Summons and Complaint can be obtained by contacting either the Clerk of the Court or the attorney for Plaintiff. If you wish legal assistance, you should immediately retain an attorney to advise you in this matter. DATED this 20thday of February, 2018. BONNER COUNTY DISTRICT COURT MICHAEL ROSEDALE Clerk of the Court By: /S/: Tatum Smith Deputy Clerk SNP LEGAL 5201 FEBRUARY 23, MARCH 2, 9, 16, 2018

SUMMONS CASE NO. CV 2017-01356 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF BONNER JOHN HANSEN and LYNDA HANSEN husband and wife, Plaintiffs, vs. RAYMOND L. CARTER and KRISTINE M. CARTER, Trustees of the Raymond and Kristine Carter Living Trust, dated October 21, 1994; and MAGGIE LYONS, Successor Trustee of the DAN AND TERESA DESHON FAMILY TRUST, and any and all heirs, beneficiaries, successors, assigns or other persons claiming any right, title or interest in and to that real property described as follows: A portion of the real property located in Section 22, Township 57 North, Range 2 West, Boise Meridian, Bonner County, Idaho, described in that certain deed recorded with the Bonner County Recorder on December 3, 1945, in Book 72 of Deeds, Page 249 as Instrument No. 18176, more particularly described as follows: The East Half (E1/2) of that real property lying between the sidelines of South Fourth Avenue in the City of Sandpoint, Idaho, from the south end of South Fourth Avenue, extending to the ordinary mean high water line of Lake Pend Oreille, as it existed as of the date of statehood and prior to construction of any dams regulating the elevation of Lake Pend Oreille, situated in the City of Sandpoint, Idaho, County of Bonner, State of Idaho, Defendants. NOTICE TO DEFENDANTS: ANY AND ALL HEIRS, BENEFICIARIES, SUCCESSORS, ASSIGNS OR OTHER PERSONS CLAIMING ANY RIGHT, TITLE OR INTEREST IN AND TO THAT REAL PROPERTY DESCRIBED IN THE CAPTION ABOVE YOU HAVE BEEN SUED BY THE ABOVE-NAMED PLAINTIFFS. READ THE INFORMATION BELOW: You have been sued by John Hansen and Lynda Hansen, husband wife, the Plaintiffs, in the District Court in and for County, Idaho, Case No. CV 2017-01356. The nature of the claim against you is an action for Quiet Title and Declaratory Relief. Any time after 20 days following the last publication of this Summons, the Court may enter a judgment against you without further notice, unless prior to that time you have filed a written response in the proper form, including the Case No., and paid any required filing fee to the Clerk of the Court at Bonner County District Court, 215 South First Avenue, Sandpoint, ID 83864, Phone 208-265-1432, and served a copy of your response on the Plaintiffs' attorney at Featherston Law Firm, Chtd., 113 South Second Avenue, Sandpoint, Idaho, 83864, Phone: 208-263-6866. A copy of the Summons and Complaint can be obtained by contacting either the Clerk of the Court or the attorney for Plaintiffs. If you wish legal assistance, you should immediately retain an attorney to advise you in this matter. DATED this 20th day of February, 2018. BONNER COUNTY DISTRICT COURT, MICHAEL ROSEDALE Clerk of the Court By: /S/ Tatum Smith, Deputy Clerk SNP LEGAL 5202 FEBRUARY 23, MARCH 2, 9, 16, 2018

NOTICE OF APPLICATION Pursuant to Section 58-104(g) and 58-1301, et seq., Idaho Code (The Lake Protection Act) and rules of the State Board of Land Commissioners, notice is hereby given that Mark & Robin Arnold has made application to install 100 feet of riprap for erosion control. Location: Riley Creek Park Road, Pend Oreille River, Laclede, Idaho, in Section 31 Township 56 North, Range 3 West; B.M., in Bonner County. Written objections to or requests for hearing in this matter must be on file with the Idaho Department of Lands, 2550 Highway 2 West, Sandpoint, Idaho 83864 within thirty (30) days after the first appearance of this notice. Specific information regarding this application may be obtained from Amidy Fuson, Resource Specialist on behalf of Navigable Waters Program - at the above address or by calling (208) 263-5104. /S/TOM FLEER, Area Manager Idaho Department of Lands SNP LEGAL 5200 FEBRUARY 23, MARCH 2, 2018