Legals for February, 9 2023

NOTICE INVITING BIDS OWNER: Kootenai County Board of County Commissioners (BOCC) 451 Government Way PO Box 9000 Coeur d’Alene, Idaho 83816 Separate sealed BIDS for the construction of: Rehabilitation Runway 6/24 & Construct Taxiway B4 Coeur d’Alene Airport, Hayden, Idaho FAA/AIP 3-16-0010-055-2022 will be received by the Owner at the Office of the BOCC, 451 Government Way 3rd floor, Coeur d’Alene, Idaho 83816 until 2:00 p.m., Tuesday, February 28, 2023 and then at said location and time, publicly opened and read aloud. Work associated with proposed improvements is generally described as follows: Schedule A: Rehabilitate Runway 6/24 Schedule B: Construct Taxiway B4 Schedule C: Runway Lighting Work generally consists of milling Runway 6/24 and replacement with bituminous pavement to rehabilitate Runway 6/24, the construction of new Taxiway B4 and associated electrical work, remove and replace HIRLs, remove and replace REILs, grading and drainage modifications, site restoration, topsoiling, mulched seeding, and other miscellaneous items. Bid Documents will be made available after 3:00 p.m., Thursday, February 9 2023. Interested bidders may obtain bid documents at www.to-engineersplanroom.com. Electronic documents in PDF format may be downloaded at no cost. Bid documents may be ordered in hard copy format for purchase at cost (nonrefundable). Bidders must register at www.to-engineersplanroom.com to be placed on the planholders list. A Prebid Conference will be held at 10:00 a.m., Wednesday, February 15, 2023 at the Airport Manager’s Office, 10375 Sensor Ave, Hayden, Idaho 83835. Attendance is highly recommended, not mandatory. Attendance via Zoom https://us06web.zoom.us/j/87393298753  Passcode: 188785  A Bid Guaranty, payable in cash, by cashiers check, certified check or bid bond, of 5 percent of the BID AMOUNT is required. Separate Performance and Payment Bonds each in the amount of 100 percent of the CONTRACT AMOUNT will be required. Each bidder must supply all the information required by the Bid Documents and Specifications. Kootenai County, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 U.S.C. §§ 2000d to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, national origin (including limited English proficiency), creed, sex (including sexual orientation or gender identity), age, or disability in consideration for an award. Prospective Contractors are notified that the work under this Contract is funded in part by a grant from the Federal Aviation Administration and as such this solicitation and any resulting contract are subject to the requirements of the Buy America Preference; Civil Rights – Title VI Assurance; Davis Bacon; Debarment and Suspension; Disadvantage Business Enterprise; Foreign Trade Restriction; Lobby Federal Employee; and Recovered Materials contract provisions. By submitting a bid/proposal under this solicitation, the bidder or offeror certifies that neither it nor its principals are presently debarred or suspended by any Federal department or agency from participation in this transaction. All contracts and subcontracts that result from this solicitation incorporate by reference the provisions of 29 CFR part 201, et seq, the Federal Fair Labor Standards Act (FLSA), with the same force and effect as if given in full text. The FLSA sets minimum wage, overtime pay, recordkeeping, and child labor standards for full and part-time workers. The Contractor has full responsibility to monitor compliance to the referenced statute or regulation. The contractor must address any claims or disputes that arise from this requirement directly with the U.S. Department of Labor – Wage and Hour Division. No contractor, subcontractor, or specialty contractor shall be required to have a current license as a Contractor in the State of Idaho in order to submit a bid or proposal on this project; prior to award and execution of the Contract, the successful bidder shall secure an Idaho Public Works Contractor’s License. Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity: 1. The Offeror’s or Bidder’s attention is called to the “Equal Opportunity Clause” and the “Standard Federal Equal Employment Opportunity Construction Contract Specifications” set forth herein. 2. The goals and timetables for minority and female participation, expressed in percentage terms for the Contractor’s aggregate workforce in each trade on all construction work in the covered area, are as follows: Goals for minority participation for each trade 3.0% Goals for female participation in each trade 6.9% These goals are applicable to all of the Contractor’s construction work (whether or not it is Federal or federally assisted) performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, it shall apply the goals established for such geographical area where the work is actually performed. With regard to this second area, the Contractor also is subject to the goals for both its federally involved and non-federally involved construction. The Contractor’s compliance with the Executive Order and the regulations in 41 CFR Part 60-4 shall be based on its implementation of the Equal Opportunity Clause, specific affirmative action obligations required by the specifications set forth in 41 CFR 60-4.3(a) and its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade, and the Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor or from project to project for the sole purpose of meeting the Contractor’s goals shall be a violation of the contract, the Executive Order and the regulations in 41 CFR Part 60-4. Compliance with the goals will be measured against the total work hours performed. 3. The Contractor shall provide written notification to the Director of the Office of Federal Contract Compliance Programs (OFCCP) within 10 working days of award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the name, address, and telephone number of the subContractor; employer identification number of the subContractor; estimated dollar amount of the subcontract; estimated starting and completion dates of the subcontract; and the geographical area in which the subcontract is to be performed. 4. As used in this notice and in the contract resulting from this solicitation, the “covered area” is the State of Idaho, Kootenai County, and the City of Hayden. All prospective bidders are directed to the Instructions for Bidders for discussion of Bid policies, procedures, and requirements. The Owner reserves the right to reject any and all Bids, waive any and all informalities, negotiate contract terms with the successful Bidder, and disregard all non-conforming, non-responsive, or conditional Bids. The requirements of 49 CFR Part 26, Regulations of the U.S. Department of Transportation, apply to this contract. It is the policy of Kootenai County to practice nondiscrimination based on race, color, sex, or national origin in the award or performance of this contract. The Owner encourages participation by all firms qualifying under this solicitation regardless of business size or ownership. For DOT Assisted Contracts during Federal Fiscal Years, Coeur d’Alene Airport has adopted an overall three-year DBE Goal of 1.10% (0.0% Race Conscious and 1.10% Race Neutral). Kootenai County, Idaho /s/Leslie Duncan, Chair /s/Teri Johnston, Deputy Clerk Legal#10070 AD#4769 February 9,16, 2023

PROBATE NOTICE TO CREDITORS RCW 11.40.030 NO. 23-4-00136-32 SUPERIOR COURT OF WASHINGTON IN AND FOR SPOKANE COUNTY In the Matter of the Estate of: ANNETTE D. KISH, Deceased. The Personal Representative named below has been appointed as Personal Representative of this estate. Any person having a claim against the deceased must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the Personal Representative or the Personal Representative’s attorney at the address stated below, a copy of the claim, and filing the original of the claim with the Court in which the probate proceedings were commenced. The claim must be presented within the later of: (1) thirty days after the Personal Representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); OR (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both Decedent’s probate and nonprobate assets. PERSONAL REPRESENTATIVE: /s/RAYMOND T. KISH ATTORNEYS FOR PERSONAL REPRESENTATIVE LUKINS & ANNIS, P.S. By/s/DAVID P. WEBSTER WSBA #41047 ADDRESS FOR MAILING OR SERVICE DAVID P. WEBSTER Lukins & Annis, P.S. 717 W. Sprague Ave., Suite 1600 Spokane, WA 99201-0466 COURT OF PROBATE PROCEEDINGS AND CAUSE NUMBER: Superior Court, Spokane County, Washington Cause No. 23-4-00136-32 Legal#10082 AD#4834 January 26, February 2, 9, 2023 _________________________

LEGAL NOTICE The following application(s) have been filed to appropriate the public waters of the State of Idaho: 95-18400 SUNSHINE TRUST PO BOX 1010 ATHOL, ID 83801 Point of Diversion  NENW  S15 T53N R03W  KOOTENAI County Source GROUND WATER  Use: DOMESTIC 01/01 to 12/31 0.16 CFS Use: IRRIGATION 04/01 to 10/31 0.03 CFS Total Diversion: 0.19 CFS Date Filed: 01-18-2023 Place Of Use: DOMESTIC,IRRIGATION T53N R03W S15 NENW Total Acres: 1  95-18402 STERLING & MARILYNN SNYDER FAMILY TRUST PO BOX 112 ATHOL, ID 83801 Point of Diversion  SESW  S35 T53N R03W  KOOTENAI County Source UNNAMED STREAM  Tributary SINKS Use: IRRIGATION STORAGE 01/01 to 12/31 20 AF Use: IRRIGATION FROM STORAGE 04/01 to 10/31 20 AF Total Diversion: 20 AF Date Filed: 01-20-2023 Place Of Use: IRRIGATION FROM STORAGE T53N R03W S35 NESW,NWSW,SWSW,SESW Place Of Use: IRRIGATION STORAGE T53N R03W S35 SESW Total Acres: 7  95-18403 ERIN M KINGSBURY COLBY G KINSBURY 17116 N RESERVOIR RD RATHDRUM, ID 83858-7462 Point of Diversion  SWNE  S25 T52N R05W  KOOTENAI County Source GROUND WATER  Point of Diversion  SENE  S25 T52N R05W  KOOTENAI County Source GROUND WATER  Use: DOMESTIC 01/01 to 12/31 0.06 CFS Use: STOCKWATER 01/01 to 12/31 0.02 CFS Use: IRRIGATION 03/15 to 11/15 0.08 CFS Total Diversion: 0.16 CFS Date Filed: 01-20-2023 Place Of Use: DOMESTIC,IRRIGATION,STOCKWATER T52N R05W S25 SENE Total Acres: 2.5  Permits will be subject to all prior water rights. For additional information concerning the property location, contact the Northern office at (208)762-2800; or for a full description of the right(s), please see https://idwr.idaho.gov/apps/ExtSearch/WRApplicationResults/. Protests may be submitted based on the criteria of Idaho Code § 42-203A. Any protest against the approval of this application must be filed with the Director, Dept. of Water Resources, Northern Region, 7600 N MINERAL DR STE 100, COEUR D ALENE ID 83815-7763 together with a protest fee of $25.00 for each application on or before 2/21/2023. The protestant must also send a copy of the protest to the applicant. GARY SPACKMAN, Director Legal#10122 AD#5024 February 2, 9, 2023 _________________________

NOTICE OF HEARING ON NAME CHANGE Case No. CV28-23-0621 IN THE DISTRICT COURT FOR THE FIRST JUDICIAL DISTRICT FOR THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI IN RE: Sarah Mckenzie, A petition to change the name of Sarah Cecelia Parker Mckenzie, now residing in the City of Post Falls, State of Idaho, has been filed in the District Court in Kootenai County, Idaho. The name will change to Sarah Cecelia May Mallory. The Reason for the change in name is: Middle is personal, last name due to marriage. A hearing on the petition is scheduled for 1:30 o’clock p.m. on March 27, 2023 at the Kootenai County Courthouse. Objections may be filed by any person who can show the court a good reason against the name change. Date: 1-27-23 /s/Jennifer Locke CLERK OF THE DISTRICT COURT /s/Kathleen Carr Deputy Clerk Legal#10129 AD#5108 February 2, 9, 16, 23, 2023 _________________________

NOTICE TO CREDITORS Case No. CV28-22-7682 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI In the Matter of the Estate of GEORGE EDWARD LYLES, JR. Deceased.   NOTICE is hereby given that George Edward Lyles, III, has been appointed personal representative of the above-named decedent. All persons having claims against the decedent or the estate are required to present their claims within four months after the date of the first publication of this Notice to Creditors or said claims will be forever barred. Claims must be presented to the undersigned at the address indicated, and filed with the Clerk of the Court. DATED this 30 day of January 2023. /s/George Edward Lyles, III, c/o David W. Lohman, P.A. Attorney At Law Post Office Box 2332 Coeur d’Alene, ID 83816 Legal# 10134 AD#5136 February 2, 9, 16, 2023 _________________________

NOTICE OF HEARING ON NAME CHANGE Case No. CV28-23-0671 IN THE DISTRICT COURT FOR THE FIRST JUDICIAL DISTRICT FOR THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI IN RE: Peter Faucher, A petition to change the name of Peter James Faucher, now residing in the City of Coeur d’ Alene, State of Idaho, has been filed in the District Court in Kootenai County, Idaho. The name will change to Peter Jones Faucher. The Reason for the change in name is: to honor my grandmother. A hearing on the petition is scheduled for 1:30 o’clock p.m. on March 13, 2023 at the Kootenai County Courthouse. Objections may be filed by any person who can show the court a good reason against the name change. Date: Jan. 31, 2023 /s/Jennifer Locke CLERK OF THE DISTRICT COURT /s/ Deputy Clerk Legal#10135 AD#5142 February 2, 9, 16, 23, 2023 _________________________

NOTICE TO CREDITORS Case No. CV28-23-0428 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI IN THE MATTER OF THE ESTATE OF: MARGERY L. CAPAUL,             Deceased. NOTICE IS HEREBY GIVEN that the undersigned have been appointed Co-Personal Representatives of the above-named estate. All persons having claims against the said decedent are required to present their claims within four (4) months after the date of the first publication of this Notice or said claims will be forever barred. Claims must be presented to DIANA R. GUILD and KATHLEEN M. CAPAUL, Co-Personal Representatives of the above Estate, c/o Lake City Law Group PLLC at 120 E. Lake St. Ste. 202, Sandpoint, ID 83864, and filed with the Court. DATED this 6th day of February, 2023. /s/Diana R. Guild Co-Personal Representative DATED this 6th day of February, 2023. /s/ Kathleen M. Capaul Co-Personal Representative FONDA L. JOVICK, ISBA #7065 LAKE CITY LAW GROUP PLLC 120 E. Lake St. Ste. 202 Sandpoint, ID 83864 Telephone: (208) 448-1300 Facsimile: (208) 448-2100 [email protected] Legal#10168 AD#5332 February 9, 16, 23, 2023 _________________________

Lakes Highway District 2023 Road Improvement Projects Notice of Advertisement for Bids Separate sealed bids for the District’s 2023 Road Improvements Projects will be received by Lakes Highway District, Kootenai County, Idaho, the Owner, at the Lakes Highway District Office located at 11341 N. Ramsey Road, Hayden Lake, Idaho 83835 until 10:00 a.m. prevailing local time Thursday, March 2nd , 2023. Bids will then be publically opened and read aloud. The projects generally consist of asphalt paving. A pre-bid walk through will begin at the Lakes Highway District Office on February 21st  at 10:00 a.m. The Contract Documents may be examined at the following location: • Spokane Regional Plan Center, 209 N. Havana, Spokane WA 99202 • Lakes Highway District, 11341 N. Ramsey Road, Hayden, Idaho 83835 Copies of the Contract Documents may be obtained at the Lakes Highway District Office upon payment of Thirty Dollars ($30.00) for each set. Payment shall be made to the Lakes Highway District and is non-refundable. The Owner waives the right to waive any formality or to reject any or all of the bids. Davis Bacon Wages do not apply to this project. Each Bidder must deposit, with their bid, security in the amount, form and subject to the conditions provided in the Instructions to Bidders. No Bidder may withdraw their bid within sixty (60) days after the date of the opening thereof. Dated this 9th day of February 2023. /s/ Eric W. Shanley, P.E. Director of Highways Legal#10170 AD#5366 February 9, 16, 23, 2023 _________________________

SUMMONS NO. CV28-22-4118 IN THE FIRST JUDICIAL DISTRICT IN AND FOR THE  STATE OF IDAHO COUNTY OF KOOTENAI HORIZON CREDIT UNION, Plaintiff, v. BRANDON K. WOODHOUSE and JANE DOE WOODHOUSE, husband and wife and the marital community composed thereof, Defendants. TO : ALL NAMED DEFENDANTS YOU HAVE BEEN SUED BY THE ABOVE-NAMED PLAINTIFF(S) HORIZON CREDIT UNION, IN THE DISTRICT COURT IN AND FOR KOOTENAI COUNTY IDAHO, CASE NO. CV28-22-4118. The nature of the claim against you is a deficiency after repossession and defendants failure to pay. Any time after 21 days following the last publication of this summons, the court may enter a judgment against you without further notice, unless prior to that time you have filed a written response in the proper form, including the Case No., and paid any required filing fees to the Clerk of the Court at 324 W Garden Ave, Coeur d’Alene, ID 83814, (208)446-1650, and served a copy of your response on the Plaintiff’s attorney at 1235 N. Post, Ste 100, Spokane, WA 99201 A copy of the Summons and Complaint can be obtained by contacting either the Clerk of the Court or the attorney for Plaintiff.   If you wish legal assistance, you should immediately retain an attorney to advise you in this matter DATED this 1/27/20231:26 pm. JENNIFER LOCKE KOOTENAI COUNTY DISTRICT COURT By: /s/DEPUTY CLERK Benjamin D. Phillabaum Phillabaum, Ledlin, Matthews & Sheldon, PLLC. 1235 N. Post, Suite 100 Spokane, Washington 99201 (509) 838-6055 (509) 625-1909 (fax) ISB 10505 [email protected] Legal#10172 AD#5382 February 9, 16, 23, March 2, 2023 _________________________

SUMMONS To: REBECCA PEREZ You have been sued by CREDIT ACCEPTANCE CORPORATION , the Plaintiff, in the FIRST District Court in and for KOOTENAI COUNTY, Idaho, Case No. CV28-22-5733. The nature of the claim against you is collection of money owed by you. Any time after 21 days following the last publication of this summons, the court may enter a judgment against you without further notice, unless prior to that time you have filed a written response in the proper form, including the Case No., and paid any required filing fee to the Clerk of the Court at 501 Government Way, Coeur d’Alene, ID, telephone (208) 466-1160,, and served a copy of your response on the Plaintiff’s attorney MICHAEL J. ARCHIBALD, #8476 at M2 Law Group PC, P.O. Box 330, Meridian, ID 83680, telephone (208) 336-3331. A copy of the Summons and Complaint can be obtained by contacting either the Clerk of the Court or the attorney for Plaintiff. If you wish legal assistance, you should immediately retain an attorney to advise you in this matter. Dated:   1/30/2023 09:33 AM    JENNIFER LOCKE KOOTENAI COUNTY District Court By  /s/ Lori Grilley      Deputy February 9, 16, 23, 2023 March 2, 2023 _________________________

GREENFERRY WATER AND SEWER DISTRICT NOTICE  Public Hearing on an Increase in the Capital Reserve Fee The Board of Directors of the Greenferry Water and Sewer District will hold a public hearing on February 21, 2023 at 5:30 PM at the Post Falls Library, 821 N. Spokane Street, Post Falls, Idaho, to consider increasing the Capital Reserve Fee, from $15.00 per month to $25.00 per month. The reason for the increase is to cover the bond debt and to fund future capital improvements. The $35.00 monthly fee for operations will be unchanged. Residents are encouraged to attend the hearing and be heard on the issue.  Legal#10175 AD#5404 February 9, 14, 2023 _________________________

NOTICE OF HEARING ON NAME CHANGE Case No. CV28-23-0850 IN THE DISTRICT COURT FOR THE FIRST JUDICIAL DISTRICT FOR THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI IN RE: Joseph Scott Cruz-Aedo, A petition to change the name of Joseph Scott Cruz-Aedo, now residing in the City of Coeur d’Alene, State of Idaho, has been filed in the District Court in Kootenai County, Idaho. The name will change to Joseph Scott Cruzaedo-Wagner. The Reason for the change in name is: it is the name I have been using since I was 5 years old. A hearing on the petition is scheduled for 1:30 o’clock p.m. on March 20, 2023 at the Kootenai County Courthouse. Objections may be filed by any person who can show the court a good reason against the name change. Date: 2/6/2023 /s/Jennifer Locke CLERK OF THE DISTRICT COURT /s/Bobee Deglman Deputy Clerk Legal#10179 AD#5422 February 9, 16, 23, March 2, 2023 _________________________