Legals for November, 26 2025

NO. 31655 ADVERTISEMENT FOR BIDS BLACKFEET TRIBE BROWNING, MT BIA ROUTE 23 (BIRCH CREEK ROAD) ASPHALT OVERLAY Sealed bids for the construction of the Project will be received by the Blackfeet Tribe, at the office of Rick Ollinger, Blackfeet Tribal Transportation, P.O. Box 850, 640 All Chiefs Road, Browning, MT, 59417, until 10:00am MST, December 10th, 2025 at which time they will be publicly opened and read aloud at the Blackfeet TERO conference room located at 65 Blackweasel Road, Browning, MT, 59417. The Project includes the following Work: Project is generally for the construction of approximately 13 miles of asphalt pavement overlay along BIA Route 23 Birch Creek Road. This work includes crushed aggregate course - Type “A” 2,911 TON, Plant Mix Surfacing GR S-3/4 IN 37,404 TON, Asphalt Cement PG 58-28 2,319 TON, route crack sealant, Cover-Type 1 231,382 SY, Cold Milling 3,996 SY, Striping 731 GAL, and Quality Control Testing. Information and Bidding Documents for the Project are available at www.kljeng.com “Projects for Bid” or www.questcdn.com. You may download the digital plan documents for $22 by inputting Quest project #9923896 on the website’s Project Search page. Please contact QuestCDN at (952) 233-1632 or [email protected] for assistance in free membership registration, downloading, and working with this digital project information. Bidding Documents may be downloaded from the designated website. Prospective Bidders are urged to register with the designated website as a plan holder, even if Bidding Documents are obtained from a plan room or source other than the designated website in either electronic or paper format. The designated website will be updated periodically with addenda, lists of registered plan holders, reports, and other information relevant to submitting a Bid for the Project. All official notifications, addenda, and other Bidding Documents will be offered only through the designated website. Neither Owner nor Engineer will be responsible for Bidding Documents, including addenda, if any, obtained from sources other than the designated website. The Issuing Office for the Bidding Documents is: KLJ, 1830 3rd Avenue East Suite 201, Kalispell, MT 59901. Prospective Bidders may obtain or examine the Bidding Documents at the Issuing Office, by appointment, on Monday through Friday between the hours of 9:00am – 5:00pm and may obtain copies of the Bidding Documents as described above. Bidding Documents may be purchased from the Issuing Office, by appointment, during the hours indicated above. Printed documents are available for a non-refundable cost of $52 per set. Cost does not include shipping charges. Upon Issuing Office’s receipt of payment, printed Bidding Documents or electronic documents on USB drive will be sent via the prospective Bidder’s delivery service. Make checks for Bidding Documents payable to KLJ. Please contact us at 406-300-7107 if you have any questions or to schedule obtaining documents. Each bid must be accompanied by a separate envelope containing the contractor’s license and bid security. The bid security must be in a sum equal to five per cent (5%) of the full amount of the bid and must be in the form of a bidder’s bond. A bidder’s bond must be executed by the bidder as principal and by a surety company authorized to do business in this state, conditioned that if the principal’s bid is accepted and the contract awarded to the principal, the principal, within ten (10) days after notice of the award, shall execute a contract in accordance with the terms of the bid and the bid bond and any condition of the governing body. If a successful bidder does not execute a contract within ten (10) days allowed, the bidder’s bond must be forfeited to the governing body and the project awarded to the next lowest responsible bidder. All bidders must be licensed for the full amount of the bid as required by the Montana Department of Labor and Industry. A contractor must be the holder of a license at least ten (10) days before the date set for receiving bids, to be a qualified bidder. The successful Bidder will be required to furnish Contract Performance and Payment Bonds in the full amount of the contract. Contracts shall be awarded on the basis of the lowest responsive bid in compliance with the Blackfeet TERO regulations, submitted by a responsible bidder for the aggregate sum of all bid items. One (1) Contract will be awarded for the work. All bids will be contained in a sealed envelope, as above provided; plainly marked showing that such envelope contains a bid for the above project. In addition, the bidder shall include the following information within such an envelope: 1. Bid Form 2. Bid Bond 3. Copy of Montana Contractor’s License or certificate of renewal. 4. Acknowledgement of the Addenda. No Bid will be read or considered which does not fully comply with the above provisions as to Bond and licenses and any deficient Bid submitted will be resealed and returned to the Bidder immediately. The Owner reserves the right to reject any and all bids, to waive any informality in any bid, to hold all bids for a period not to exceed 15 days from the date of opening bids, and to rebid the project until a satisfactory bid is received. For all further requirements regarding bid submittal, qualifications, procedures, and contract award, refer to the Instructions to Bidders that are included in the Bidding Documents. This Advertisement is issued by: Owner: Blackfeet Tribe By: Rick Ollinger Title: Transportation Director Date: November 5th, 2025 November 12, 26, 2025 MNAXLP __________________________

NO. 31664 COMMUNITY DEVELOPMENT BLOCK GRANT PUBLIC HEARING A combined hearing will be held by the City of Kalispell and Flathead County, at 1:00 p.m., December 4, 2025, in the Kalispell City Council Chambers located in Kalispell City Hall: 201 First Avenue East, Kalispell, MT 59901. The public can participate in person or via videoconferencing. Register to join the video conference by email [email protected] or by phone 406-758-7713.   The City of Kalispell and Flathead County are eligible to submit an application to the Montana Department of Commerce for a Community Development Block Grant (CDBG) and/or a Montana Home Investment Partnership Program Grant (HOME). The grant programs and activities eligible for funding will be fully described. Everyone will be given the opportunity to submit comments regarding community needs and projects for consideration. Comments may be given orally at the hearing or by mail to City of Kalispell Development Services, 201 1st Avenue East, Kalispell, Montana 59901 or by email [email protected] before 1:00 p.m. on Thursday, December 04, 2024.  For more information or to register for the hearing via Zoom, please contact the City of Kalispell Development Services Department via email [email protected] or phone 406-758-7713 or visit https://www.kalispell.com/634/Community-Development-Block-Grant. CDBG or HOME application guidelines are available for review on the Montana Department of Commerce website, Community Development Block Grant (CDBG) Program - Community MT. November 16, 26, 2025 MNAXLP __________________________

NO. 31670 Sara E. Smith Clerk of District Court Flathead County Justice Center 920 South Main Street Kalispell, MT 59901 (406) 758-5906 IN THE DISTRICT COURT OF THE ELEVENTH JUDICIAL DISTRICT OF THE STATE OF MONTANA, IN AND FOR THE COUNTY OF FLATHEAD IN THE MATTERS OF: G.H., D.H., D.H., D.H., YOUTHS IN NEED OF CARE. SUMMONS FOR PUBLICATION To: Julianne Kramer, birth mother of the above-named child: YOU ARE HEREBY NOTIFIED that a Petition has been filed in the above-entitled Court by the Montana Department of Public Health and Human Services, Child and Family Services Division, 121 Financial Drive, Suite C, Kalispell, MT 59901, requesting termination of parental rights and permanent legal custody. NOW, THEREFORE, YOU ARE HEREBY DIRECTED to appear on Thursday, December 11, 2025 at 9:00 AM before the Honorable Paul Sullivan, District Judge, Department 2, Flathead County Justice Center, 920 South Main Street, Third Floor, Kalispell, Flathead County, Montana, then and there to show cause, if any you may have, why the Petition should not be granted. G.H. was born on January 12, 2011. D.H. was born on August 20, 2014. D.H. was born on November 28, 2015. D.H. was born on August 16, 2019. The birth mother is Julianne Kramer. You have the right to representation by an attorney in these proceedings. If you are unable to afford an attorney, the Court will appoint an attorney to represent you. Your failure to appear at the hearing constitutes a denial of your interest in the above-named child, which denial may result, without further notice of this proceeding or any subsequent proceedings, in the Court entering judgment by default against you for all relief requested in the Petition. A copy of the Petition is filed with the Clerk of District Court for the Eleventh Judicial District Court in and for Flathead County, 920 South Main, Third Floor, Kalispell, Montana, 59901, telephone (406) 758-5870.   WITNESS my hand and Seal of this Court this 13 day of November, 2025. SARA SMITH Clerk of District Court By:/s/ Kristen Skees Deputy Clerk (SEAL) November 19, 26 and Decmeber 3, 2025 MNAXLP __________________________

NO. 31671 McCreedy Law Office, PLLC, 1104 S. Higgins Ave., Missoula, MT 59801, (406) 239-6273, [email protected]. Attorney for Estate.  MONTANA TWENTIETH JUDICIAL DISTRICT COURT, LAKE COUNTY, In the Matter of the Estate of Kaye F. McCreedy, Deceased, Cause No. DP-25-72. NOTICE TO CREDITORS: Phil McCreedy was appointed Personal Representative of the above-named estate on 11/12/2025. All persons having claims against the estate must present their claims within four months of the date of first publication of this notice or said claims will be forever barred. Claims must be mailed to Phil McCreedy, the Personal Representative, certified mail, return receipt requested, at 1104 S. Higgins, Missoula, MT 59801, or filed with the Clerk of the Eleventh Judicial District Court, Flathead County. Dated November 14, 2025. November 19, 26 and December 3, 2025 MNAXLP __________________________

NO. 31685 The contents of unit 29, rented by Kevin Fogel, at Green’s Mini Storage, located at 1410 Hwy 93 North, Victor Mt., will be sold or disposed of on or after 12-20-2025, for non-payment of rents. November 26 and Decemeber 3, 2025 MNAXLP __________________________

NO. 31687 Doug Scotti FRAMPTON PURDY LAW FIRM 530 West 19th Street #301 Whitefish, MT 59937 (406) 862-9600 [email protected] Attorneys for Plaintiffs MONTANA ELEVENTH JUDICIAL DISTRICT COURT, FLATHEAD COUNTY THE PATRICK AND LINDA McGINNIS FAMILY TRUST, its heirs successors and assigns, and PATRICK McGINNIS, Plaintiffs,  -vs- KAYLAN HAHN, and JOHN DOE/JANE DOE(S) 1 – 5, Defendants. Cause No. DV-22-1166C Judge Heidi Ulbricht SUMMONS  BY PUBLICATION THE STATE OF MONTANA sends greetings to Defendant KAYLAN HAHN: The above-named Plaintiffs have filed a Preliminary Injunction against you, enjoining you from keeping, disposing of, or destroying, any of the personal property as identified therein. YOU ARE HEREBY SUMMONED to comply with the Preliminary Injunction dated November 3, 2022 in this action, filed in the office of the Clerk of this Court, a copy of which is herewith served upon you in the County wherein you reside, to identify the location(s) of personal property at issue, provide full and unfettered access to all of the items of property that remain in Defendant’s possession, custody or control, and to serve upon Plaintiff’s Attorney the specific location(s) wherein each item of said personal property remains, within thirty (30) days after the service of this Summons, exclusive of the day of service. Service shall be effectuated following the publication of this Summons three times, once each week for three successive weeks, in a newspaper in Flathead County, Montana. In case of your failure to comply or appear, judgment will be taken against you, by default, for the relief demanded in the Preliminary Injunction. WITNESS MY HAND AND THE SEAL OF SAID COURT THIS18 DAY OF NOVEMBER, 2025. Sara Smith CLERK OF DISTRICT COURT By: /s/Jamie Hadley Deputy Clerk (SEAL) November 26 and December 3, 10, 2025 MNAXLP __________________________

NO. 31689 TANKO LAW OFFICE KATHERINE C. TROIANO, ESQ. Montana Bar No. 14440 638 Nucleus Ave, Suite 103 PO Box 2573 Columbia Falls, MT 59912 Tel: (406) 897-7133 Fax: (406) 897-7150 Email: [email protected] Web: www.tankolaw.com Attorney for Personal Representative MONTANA ELEVENTH JUDICIAL DISTRICT COURT, FLATHEAD COUNTY In Re: The Estate of: IRENE MARY ANDERSON, Deceased. Cause No: DP-15-2025-0000277-FT Paul Sullivan District Court Judge NOTICE TO CREDITORS NOTICE IS HEREBY GIVEN that the undersigned has been appointed Personal Representative of the above-named Estate. All persons having claims against the said deceased are required to present their claims within four (4) months after the date of the first publication of this Notice or said claims will be forever barred. Claims must either be mailed to JEROME C. ANDERSON, the Personal Representative, return receipt, to: c/o Tanko Law Office, PO Box 2573, Columbia Falls, MT 59912 or filed with the Clerk of the above Court. DATED this 30th day of October, 2025. /s/ Jerome C. Anderson JEROME C. ANDERSON, Personal Representative November 26 and December 3, 10, 2025 MNAXLP __________________________

NO. 31690 PUBLIC NOTICE Notice of Application for Air Quality Major Open Burning Permit (pursuant to Section 75-2-211, MCA, and ARM Title 17, Chapter 8, Subchapter 6, Open Burning), Flathead Ridge Ranch LLC has filed on or about 11/20/2025 an application for a major open burning permit from the Air, Energy & Mining Division of the Montana Department of Environmental Quality (Department). Applicant(s) seeks approval of its/their application to open burn forest slash and brush at Flathead and Lake Counties Any member of the public with questions or who wishes to receive notice of the Department’s determination, and the location where a copy of the application and the Department’s analysis of it can be reviewed, or to submit comments on the application, must contact the Department at 1520 East Sixth Ave., P.O. Box 200901, Helena, Montana 59620-0901, phone (406) 444-3490. Any comments on the application must be submitted to the Department within 20 days after publication of this notice or filing of the application, whichever is later. The Department’s decision to approve or deny an application for a major open burning permit may be reviewed by the Board of Environmental Review (Board) according to the following procedure: When the Department approves or denies the application for a major open burning permit under this section, a person who is jointly or severally adversely affected by the Department’s decision may request, within 15 days after the Department renders its decision, upon affidavit setting forth the grounds therefor, a hearing before the Board. A hearing shall be held under the provisions of the Montana Administrative Procedures Act. The Department’s decision on the application is not final unless 15 days have elapsed and there is no request for a hearing under this section. The filing of a request for a hearing postpones the effective date of the Department’s decision until the conclusion of the hearing and issuance of a final decision by the Board. November 26, 2025 MNAXLP __________________________

NO. 31691 Montana 11th Judicial District Court Flathead County In the Matter of the Name Change of Bertrand Remigereau: Bertrand Remigereau Cause No.: DV-25-1563 Notice of Hearing on Name Change DAN WILSON This is notice that Petitioner has asked the District Court for a change of name from Bertrand Remigereau to Remi Bertrand. The hearing will be on 01/06/2026 at 1:30 p.m. The hearing will be at the Courthouse in Flathead County. Date: November 21, 2025 Sara Smith Clerk of District Court By: /s/Jamie Hadley Deputy Clerk of Court (SEAL) November 26 and December 3, 10, 17, 2025 MNAXLP __________________________